Carteret County Civicplus #100926CHW

Carteret County Courthouse Window, Storefront, and Curtain-Wall Replacement

Carteret County Government is seeking a turnkey replacement of window, storefront, door, and curtain-wall systems at its occupied courthouse in Beaufort, North Carolina. - Buyer: Carteret County Government, Purchasing Department. - OEM: Trulite; the bid schedule identifies Trulite Series CT501 as the base product, with approved equals allowed. - Products requested: - Approximately 154 fixed-pane, impact-rated windows with white aluminum frames and factory-tinted glass; no grids between panes. - Two impact-rated single storefront doors with sidelights. - One impact-rated, two-story north breezeway storefront system with double doors. - One non-impact-rated, first-story courtyard storefront system and doors. - Two non-impact-rated, two-story courtyard curtain-wall windows. - Non-impact-rated, second-story courtyard fixed-pane windows; quantity not specified. - One impact-rated, two-story west-wall curtain-wall system. - Work includes field verification, removal and disposal of window treatments, permits if required, installation, interior and exterior trim and finishing, repair of installation damage, temporary weather protection, debris control, and cleanup. - The courthouse must remain secure, accessible, and operational during construction. Requirements include phased work, a logistics plan, full-time supervision, dust/noise/debris control, security coordination, and advance coordination for disruptive work. - The west-wall curtain-wall system has stated performance criteria for deflection, water penetration, air leakage, and thermal transmittance. Impact-rated glazing must meet the cited impact-resistance standards. - The project duration is 300 days, starting after submittals are approved and materials are on-site. Late completion is subject to stated liquidated damages of $1,000 per day.

Description

Carteret County Government is seeking sealed bids for turnkey replacement of windows and storefront systems at the Carteret County Courthouse in Beaufort, North Carolina. The work includes replacing approximately 154 windows, storefront doors, storefront systems, and curtain-wall windows, along with related labor, materials, installation, finishing, and cleanup. The courthouse will remain occupied and operational during construction, so the contractor must coordinate phasing, security, access, and safety with the County. A 5% bid bond and three copies of the bid are required.

View original listing