Santa Cruz Opengov #IFB No. ED-0330

Santa Cruz Gateway Landscape Improvements – Invitation for Bid for landscape construction services at Ocean Street and Plymouth Street.

The City of Santa Cruz is seeking bids from qualified landscape contractors for the Santa Cruz Gateway Landscape Improvements project at Ocean Street and Plymouth Street. - Government Buyer: - City of Santa Cruz, Economic Development and Housing department - Scope of Work: - Demolition of existing structures and site preparation - Installation of irrigation systems - Planting and landscape establishment - Concrete work - Lighting and low-voltage electrical work - Products/Services Requested: - Irrigation system installation - Lighting and low-voltage electrical components - Concrete construction - Planting of vegetation - Demolition, site and soil preparation, landscape establishment - OEMs and Vendors: - No specific OEMs or vendors are named in the solicitation - Unique/Notable Requirements: - Contractors must demonstrate relevant experience and provide references - Adherence to city standard specifications and details is required - Liquidated damages of $13,200 per day for project delays - Compliance with all bid requirements and city policies - Attachments include detailed specifications, bid set, project documents, and standard city requirements

Description

This solicitation is for landscape improvements at the intersection of Ocean Street and Plymouth Street in Santa Cruz, California. The scope of work includes demolition, site and soil preparation, irrigation, planting, concrete work, lighting, electrical work, and landscape establishment. Bids are due by October 24, 2026, and will be publicly opened via Zoom. The project is governed by the City of Santa Cruz's standard terms, conditions, and policies. Respondents must demonstrate experience, provide references, and comply with all bid requirements.

View original listing