Sedgwick County Sedgwickcounty #26-0084

Storm Sewer Line Repair and Improvements at Sedgwick County Main Courthouse

Sedgwick County is seeking bids for storm sewer improvements at the Main Courthouse in Wichita, KS. - Government Buyer: - Sedgwick County Board of County Commissioners - Purchasing Department, Finance Department, Wichita, KS - Scope of Work: - Identify and repair a compromised storm sewer line connecting courthouse parking drains to the city storm sewer main - Includes mobilization, excavation, pipe repair, surface restoration, and cleanup - Contractor must coordinate with Sedgwick County and the City of Wichita for traffic control, including lane reductions on Central Ave - Removal of existing cones and signs prior to work commencement - Compliance with ADA, Kansas laws, insurance, and bonding requirements - Unique Requirements: - Non-mandatory pre-bid meeting on site; subcontractors encouraged to attend - Lump sum contract; liquidated damages for delays ($250/day, increasing to $500/day after 30 days) - One-year warranty period for correction of work - No specific OEMs or vendors are named in the solicitation - Plans and specifications are available electronically; no bid document deposit required

Description

This solicitation is for storm sewer improvements at the Main Courthouse located at 525 N Main St., Wichita, KS. The project involves identifying and repairing a compromised storm sewer line that connects the courthouse surface parking drains to the city storm sewer main. The awarded contractor will coordinate traffic control plans with Sedgwick County and the City of Wichita, as westbound traffic on Central Ave has been reduced to a single lane as a precaution. A pre-bid meeting will be held on site, and bidders are encouraged to have subcontractors attend to view the site conditions.

View original listing