Stearns County Bids and Tenders #26-37

Stearns County Courthouse Landscaping, Irrigation, and Metal Railings Project

Stearns County is inviting bids for a Courthouse construction project with two main scopes: - Landscaping and Irrigation: - Removal of existing landscape materials - Installation of new soil, sod, and overseeding - Provision of new mulch and repair/replacement of landscape edging - Repair and upgrade of the irrigation system, including new pipes, heads, and valves - Metal Railings: - Supply and installation of new galvanized and painted metal handrails and guardrails - Contractors must provide all materials, labor, and equipment for both scopes - Bids must be separated for each work scope - No specific OEMs or vendors are named in the solicitation - Notable requirements include adherence to specified completion dates for each scope

Description

The County of Stearns is soliciting bids for landscaping, irrigation maintenance, and stair railings at the Courthouse. The project includes two separate work scopes: landscaping and irrigation, which involves removing existing materials, installing new soil, sod, mulch, and repairing the irrigation system; and railings, which involves providing new galvanized and painted metal handrails and guardrails. The contractor is responsible for all materials, labor, and equipment. Completion dates are September 30, 2026, for landscaping and irrigation, and October 16, 2026, for railings.

View original listing