Nueces County Publicpurchase #33340-26

AWOS Installation at Nueces County Airport

This opportunity seeks a contractor for the installation of an Automated Weather Observing System (AWOS) at Nueces County Airport in Robstown, Texas. - Government Buyer: - Nueces County Airport (Nueces County Commissioners Court) - Products/Services Requested: - Automated Weather Observing System (AWOS) - Complete system installation, including all required equipment and materials - Removal and disposal of all demolished materials and debris - Installation, testing, and commissioning services for AWOS - Quantities: - 1 complete AWOS system - 1 set of installation and commissioning services - Notable Requirements: - All materials must meet or exceed the quality of existing materials - Contractor must provide all necessary tools, equipment, and materials - Project completion required within 90 calendar days from Notice to Proceed - Liquidated damages of $200 per day for late completion - No specific OEMs or vendors are named in the solicitation - Bidders must submit bid bond, credentials, certifications, and compliance forms

Description

The Commissioners Court of Nueces County is soliciting sealed competitive bids for the installation of an Automated Weather Observing System (AWOS) at Nueces County Airport located at 3983 Wings Drive, Robstown, TX. The project requires completion within 90 calendar days after the Notice to Proceed, with liquidated damages of $200 per day for delays. The contractor must provide all tools and equipment, ensure quality materials, and handle removal and disposal of debris. Bids must include specified documents and can be submitted online or physically to the Purchasing Office.

View original listing