Opportunity
Guilford County NC MUNIS #20257
Chiller Replacement and HVAC Upgrades at Greensboro Public Health Facility
Posted
February 04, 2025
Respond By
February 27, 2025
Identifier
20257
NAICS
238220, 238290
This opportunity involves the replacement of the main chiller system at the Greensboro Public Health facility in North Carolina. - Government Buyer: - Guilford County Facilities Department, City of Greensboro Public Health, and Guilford County Facilities and Parks are the primary buyers and project managers. - OEMs and Vendors: - OEMs specified as basis of design or approved equals: Trane (ASCA 160), Carrier, Daikin, York (chillers); Cemline (buffer tank); Raychem (heat tracing); Watts (backflow preventer). - Awarded vendor: Boiler Masters Inc. - Engineering services by R.C. Pritchard Engineering Services. - Products/Services Requested: - 160-ton air-cooled scroll chiller (Trane ASCA 160 or approved equal) - 500-gallon chilled water buffer tank (Cemline or equal) - RPZ backflow preventer (Watts or equal) - Chilled water piping, valves, strainers, insulation, and accessories - Electrical switchboards, panelboards, and wiring - Heat tracing for HVAC piping (Raychem or equal) - Instrumentation and controls for HVAC - Demolition and removal of existing 170-ton chiller and associated equipment - Installation, testing, startup, balancing, and commissioning of new systems - Project management, scheduling, and compliance with minority/women-owned business participation - Unique/Notable Requirements: - Chiller must meet ASHRAE 90.1, AHRI 550/590, UL 1449, and other industry standards - 10-year compressor, parts, and labor warranty for chiller - All contractors and subcontractors must be licensed in North Carolina - Strict 90-day completion timeline from equipment receipt, with liquidated damages for late completion - Integration with existing pneumatic controls and provision for future DDC controls - Encouragement of minority and women-owned business participation - Place of Performance: - Greensboro Public Health, 1100 East Wendover Avenue, Greensboro, NC 27401
Description
This solicitation is for the replacement of the existing 170 ton air-cooled screw chiller with a new 160 ton air-cooled scroll chiller at Greensboro Public Health, located at 1100 East Wendover Avenue, Greensboro, North Carolina. The project includes demolition of the existing chiller, humidification sprayers, and associated pump and piping. The contractor must provide all required labor, tools, materials, and equipment for the replacement. Respondents or their subcontractors must be licensed to perform all required work in North Carolina. Minority-owned and women-owned business participation is encouraged.