Guilford County NC MUNIS #20062

Basement Renovation Demolition Services for Old Guilford County Courthouse

Guilford County Facilities, Parks and Property Management is seeking bids for basement renovations at the Old Guilford County Courthouse in Greensboro, NC. - Government Buyer: - Guilford County Facilities, Parks and Property Management - Project managed by Kirim McGee - Project Scope: - Selective demolition and removal of portions of the courthouse basement - Includes removal of carpet, vinyl flooring, gypsum board at partition walls, wood furring, gypsum board from window heads and jambs, and lay-in acoustic ceiling tiles - Preservation of marble wainscoting, window jambs, and metal ceiling grids is required - All labor, tools, materials, and equipment to be provided by the contractor - Services Requested: - Demolition and removal services as per architectural drawings - Unique/Notable Requirements: - 10% participation goal for minority-owned and women-owned businesses - Contractors and subcontractors must be licensed in North Carolina - Project duration is 90 calendar days from Notice to Proceed - Liquidated damages of $100 per day for delays - No specific OEMs or product part numbers are mentioned; the opportunity is open to qualified construction firms

Description

Guilford County Purchasing Department is soliciting bids for the Old Guilford County Courthouse Basement Renovations located at 301 West Market Street, Greensboro, NC. The project involves demolition and removal of selective portions of the building as per the provided drawings. Contractors must provide all required labor, tools, materials, and equipment and must be licensed to perform all required work in North Carolina. Minority-owned and women-owned business participation is encouraged. The bid submission is not electronic and must be delivered in a sealed envelope by the due date.

View original listing