Nueces County Publicpurchase #3339-26

Briscoe King Pavilion Construction and Renovation with ADA and Facility Upgrades

Nueces County Commissioners Court is seeking competitive bids for the construction and renovation of the Briscoe King Pavilion in Corpus Christi, TX. - Project includes: - Repairs and renovation of the existing pavilion structure - Construction of a new facility with site improvements for ADA accessibility and compliance - Three alternate bid options: - Removal and replacement of the roof, gutters, and downspouts at Existing Building 1 (EB1) with a standing seam metal roof - Removal and replacement of all windows at EB1 to match new windows at adjacent new construction - Removal and replacement of all existing fans at EB1 with new units - Project designed by EDR Architects - Contractors must provide all necessary tools, equipment, and materials equal to or better than existing - Removal and disposal of demolished materials and debris is required - Completion must occur within the bidder's proposed calendar days; $500 per day liquidated damages for delays - No specific OEMs or vendors are named in the solicitation

Description

The Commissioners Court of Nueces County is soliciting sealed competitive bids for the construction and renovation of the Briscoe King Pavilion located at 15820 Park Rd. 22, Corpus Christi, TX. The project includes repairs and renovation of the existing pavilion structure, construction of a new facility with ADA site improvements, and optional alternate bids for roof replacement, window replacement, and fan replacement at the existing building. Contractors are responsible for providing all tools and equipment, using materials equal or better than existing, and managing demolition debris. The contract requires completion within the bidder's proposed calendar days, with liquidated damages of $500 per day for delays.

View original listing