Opportunity
Penn Bid Bonfire #Paradise Township, Monroe County
Paradise Township solicits bids for construction of two pickleball courts and related improvements at Seven Pines Park, Monroe County, PA.
Posted
April 15, 2026
Respond By
May 08, 2026
Identifier
Paradise Township, Monroe County
NAICS
237310, 238990
Paradise Township in Monroe County, PA is seeking bids for the construction of two pickleball courts and related site improvements at Seven Pines Park. - Government Buyer: - Paradise Township (local government) - Project managed by Linder Engineering, Inc. (design firm) - Products and Services Requested: - Construction of two paved pickleball court pads - Installation of chain link perimeter fencing - Creation of a pedestrian walking path - Supply and installation of court nets (2), line painting, benches, and picnic tables - General site construction and installation services - OEMs and Vendors: - No specific Original Equipment Manufacturers (OEMs) are named in the solicitation - Unique or Notable Requirements: - Electronic bid submission via PennBid - Bid security of 10% of bid amount required - Penalties for late completion - Submission of affidavits and bid documents required - Fixed fee contract; open to all qualified bidders with no set-aside restrictions - Place of Performance: - Seven Pines Park, Paradise Township, Monroe County, PA
Description
Paradise Township is soliciting bids for the construction and installation of two pickleball courts and related improvements at Seven Pines Park in Monroe County, Pennsylvania. The project scope includes building a paved pad for the courts, installing a chain link perimeter fence, pedestrian walking path, court nets, line painting, benches, and picnic tables. Bids must be submitted electronically via PennBid by May 8, 2026, with construction expected to start by May 26, 2026, and substantial completion by June 26, 2026. Bid security equal to 10% of the bid is required, and penalties apply for delays beyond the completion date.