City of Columbia Ionwave #38/2026 Addendum 1

The City of Columbia, Missouri is seeking bids for the construction and surfacing of ten new pickleball courts at Albert-Oakland Park. - Government Buyer: - City of Columbia, Missouri - Parks and Recreation Department, Purchasing Division - Project Scope: - Construction and surfacing of ten (10) new pickleball courts - Includes all labor, materials, equipment, supervision, mobilization, demobilization, site preparation, surface preparation, striping, protection of existing conditions, and final cleanup - Surfacing must use acrylic colored surfacing systems compliant with USA Pickleball and American Sports Builders Association standards - Primary OEMs (Surfacing Systems): - Laykold - Novacrylic - TPS Court Surfaces - Approved equivalents may be considered - Products/Services Requested: - Complete surfacing of ten pickleball courts (firm, fixed price) - Construction and surfacing services for ten pickleball courts - Unique/Notable Requirements: - Compliance with prevailing wage laws (Missouri Division of Labor Standards Annual Wage Order No. 32 for Boone County) - OSHA training required - Performance and payment bonds required - One-year warranty on workmanship and materials - Liquidated damages of $100 per day for delays beyond the specified completion date - Place of Performance/Delivery: - Albert-Oakland Park, 1900 Blue Ridge Road, Columbia, MO 65202 - Contract Period: - Work must be completed by May 15, 2026, with a maximum contract term of five years and three months

The City of Columbia, Missouri, is soliciting competitive sealed bids for the surfacing of pickleball courts at Albert-Oakland Park. The project involves providing materials and installation for the court surfacing only, with specifications including a 6-inch thick concrete slab with #5 rebar on 1-foot centers. Bidders may submit responses electronically or via sealed paper bids by March 27, 2026. The contract period extends from the effective date through project completion.