# Saskatchewan Tenders #2026-27-0057

Saskatoon Office Expansion and Flow Forecast Center Construction Fit-Up

**Posted:** October 07, 2026
**Respond By:** November 06, 2026
**Identifier:** 2026-27-0057
**NAICS:** 236220

The Water Security Agency is seeking a general contractor for an approximately 10,000-square-foot expansion and Flow Forecast Center fit-up at its Saskatoon office.
- **Government buyer:** Water Security Agency (WSA), a Saskatchewan Crown corporation.
- **OEMs and vendors:** No OEMs, product brands, or prospective contractors are named in the materials; WSA is the buyer.
- **Requested work:** Turnkey construction and fit-up of Unit #40, following the architectural, mechanical, electrical, and structural drawings, hardware list, cut sheets, and building permit.
  - Scope includes permits and approvals, project and construction management, construction, quality and safety oversight, commissioning and turnover, data-cabling and fiber-optic test reports, as-built drawings, O&M manuals, and correction of deficiencies.
  - WSA will supply and install furniture and IT hardware separately. Existing glazing and temporary walls are to be reused where possible.
- **Pricing requested:** Separate prices for the complete project, Phase 1, and Phase 2, plus Phase 2 demobilization and remobilization if required. Pricing must show bonding, the contract price excluding PST, PST, and the total.
- **Phasing and requirements:** Phase 1 is to be completed before the end of its budget cycle. Phase 2 depends on budget availability and must be completed within three months of its construction start. Performance and labor-and-material payment bonds are each required at 50% of the contract price; delay damages are capped at 10% of the contract price.
- **Products and quantities:** No discrete products, product part numbers, or hardware quantities are identified in the provided summaries.

### Description

Water Security Agency is seeking quotations for fitting up an adjacent bay to its existing Saskatoon office to accommodate a new Flow Forecast Center and additional office space, in accordance with the provided design drawings. Respondents must provide pricing for the entire project, Phase 1, and Phase 2; pricing for Phase 2 demobilization and remobilization is also requested if required. Depending on bid prices, the work may be completed over two budget cycles, with Phase 1 intended to be completed and invoiced before March 31, 2027, and Phase 2 beginning in the budget cycle starting April 1, 2027.

[View original listing](https://www.sasktenders.ca/Competitions/Print?id=010ef29c-ba28-4b62-9522-353d44680264)